Version: 7.0 | Effective Date: March 24, 2026
This Terms of Service agreement is a legally binding contract between **WebUps**, accessible via webups.store, and you, the user or client. This document has been meticulously architected across 20 distinct sections to provide an exhaustive framework for professional engagement, ensuring absolute clarity, legal robustness, and full alignment with professional business standards for our high-end technology agency operations in Patna, Bihar.
By accessing webups.store or engaging our professional services, you acknowledge that you have read, understood, and voluntarily agreed to be bound by these Master Terms. If you do not agree to any part of this agreement, you must immediately cease all use of our website and services.
WebUps provides a comprehensive suite of digital services, including custom web engineering, mobile application development, e-commerce architecture, and technical UI/UX design. All services are provided on a professional project basis, with specific deliverables outlined in a separate Statement of Work (SOW).
Our services are strictly intended for professional business entities and individuals who are at least 18 years of age and possess the legal capacity to enter into a binding contract. By engaging us, you represent that you meet these eligibility requirements.
All proprietary code, designs, and intellectual property developed by WebUps remain our exclusive property until full payment is received. Upon final payment, ownership of the final deliverables is transferred to the client, while WebUps retains the right to use non-proprietary code snippets and project case studies for professional portfolio purposes.
All projects begin with a formal consultation and technical analysis. We provide detailed, itemized quotes that remain valid for 14 calendar days. A signed SOW and a non-refundable deposit are required to initiate any development work.
We operate using an agile engineering framework. Projects are divided into distinct milestones, each requiring client review and formal sign-off. Delays in client feedback or milestone approval will result in proportional shifts in the final project timeline.
Clients are responsible for providing all necessary business information, brand assets, and technical requirements in a timely manner. WebUps is not liable for delays caused by the client's failure to provide essential project data.
Our pricing is based on technical complexity and resource allocation. We utilize a milestone-based payment structure. All invoices are due within 7 calendar days of issuance. Late payments may result in the suspension of development work.
Post-launch technical support is provided for a period of 30 days to ensure a smooth transition. Ongoing maintenance, security updates, and feature enhancements are available under separate professional support agreements.
WebUps warrants that all deliverables will be engineered to professional industry standards and will function as specified in the SOW. This warranty is valid for 30 days post-launch, provided no third-party modifications have been made to the code.
To the maximum extent permitted by law, WebUps shall not be liable for any indirect, incidental, or consequential damages, including loss of profits, data, or business opportunities, arising from the use of our services or website.
You agree to indemnify and hold WebUps harmless from any claims, damages, or legal costs arising from your breach of these terms or your use of the final deliverables in a manner that violates third-party rights or laws.
Both parties agree to maintain the strict confidentiality of all proprietary business information, trade secrets, and technical data exchanged during the course of the professional engagement.
WebUps often utilizes third-party APIs and services. We are not responsible for the performance, uptime, or data practices of these third-party providers. All integrations are subject to the terms of the respective providers.
Either party may terminate the engagement for a material breach of these terms. WebUps reserves the right to suspend services for non-payment or if the client's actions compromise our professional integrity or technical infrastructure.
These terms are governed by the laws of the State of Bihar, India. Any disputes arising from this agreement shall be subject to the exclusive jurisdiction of the courts in Patna, Bihar.
WebUps is not liable for failures or delays caused by events beyond our reasonable control, including natural disasters, internet outages, or government actions.
If any provision of these terms is found to be invalid, the remaining provisions shall remain in full force and effect. These terms constitute the entire agreement between the parties regarding the use of our website.
We reserve the right to amend these terms at any time. All updates will be posted on this page with a revised "Effective Date." Continued engagement with WebUps constitutes acceptance of the amended terms.
For any legal inquiries or formal notices regarding these terms, please contact our legal department at WebUps, Kavi Raman Path, Patna City, Danapur, Phulwari, Patna, Bihar, India, or email support@webups.store.